Terms and Conditions
1.1 “PPS” means Permanent Plumbing Solutions Pty Ltd, its successors and assigns or any person acting on behalf of and with the authority of Permanent Plumbing Solutions Pty Ltd.
1.2 “Client” means the person/s ordering the Works as specified in any invoice, document or order, and if there is more than one Client is a reference to each Client jointly and severally.
1.3 “Works” means all Works or Materials supplied by PPS to the Client at the Client’s request from time to time (where the context so permits the terms ‘Works’ or ‘Materials’ shall be interchangeable for the other).
1.4 “Price” means the Price payable for the Works as agreed between PPS and the Client in accordance with clause 4 below.
2.1 The Client is taken to have exclusively accepted and is immediately bound, jointly and severally, by these terms and conditions if the Client places an order for or accepts delivery of any Works.
2.2 These terms and conditions may only be amended with PPS’s consent in writing and shall prevail to the extent of any inconsistency with any other document or agreement between the Client and PPS.
- Change in Control
3.1 The Client shall give PPS not less than fourteen (14) days prior written notice of any proposed change of ownership of the Client and/or any other change in the Client’s details (including but not limited to, changes in the Client’s name, address, contact phone or fax number/s, or business practice). The Client shall be liable for any loss incurred by PPS as a result of the Client’s failure to comply with this clause.
- Price and Payment
4.1 At PPS’s sole discretion the Price shall be either:
(a) as indicated on invoices provided by PPS to the Client in respect of Works performed or Materials supplied; or
(b) PPS’s Price at the date of delivery of the Works according to PPS’s current pricelist; or
(c) PPS’s quoted Price (subject to clause 4.2) which shall be binding upon PPS provided that the Client shall accept PPS’s quotation in writing within thirty (30) days.
(a) if a variation to the Materials which are to supplied is requested; or
(b) if a variation to the Works originally scheduled (including any applicable plans or specifications) is requested; or
(c) where additional Works are required due to the discovery of hidden or unidentifiable difficulties (including, but not limited to, hard rock barriers below the surface, iron reinforcing rods in concrete, or hidden pipes and wiring in walls etc) which are only discovered on commencement of the Works; or
(d) in the event of increases to PPS in the cost of labour or materials which are beyond PPS’s control.
4.3 At PPS’s sole discretion a non-refundable deposit may be required.
4.4 Time for payment for the Works being of the essence, the Price will be payable by the Client on the date/s determined by PPS, which may be:
(a) on completion of the Works; or
(b) before completion of the Works; or
(c) by way of progress payments in accordance with PPS’s specified progress payment schedule. Such progress payment claims may include the reasonable value of authorised variations and the value of any Materials delivered to the site but not yet installed; or
(d) the date specified on any invoice or other form as being the date for payment; or
(e) failing any notice to the contrary, the date which is seven (7) days following the date of any invoice given to the Client by PPS.
4.5 Payment may be made by cash, cheque, bank cheque, electronic/on-line banking (remittance must be provided at time of payment), credit card (plus a surcharge of up to three percent (3%) of the Price for Amex Credit Cards only), or by any other method as agreed to between the Client and PPS.
4.6 Unless otherwise stated the Price does not include GST. In addition to the Price the Client must pay to PPS an amount equal to any GST PPS must pay for any supply by PPS under this or any other agreement for the sale of the Materials. The Client must pay GST, without deduction or set off of any other amounts, at the same time and on the same basis as the Client pays the Price. In addition the Client must pay any other taxes and duties that may be applicable in addition to the Price except where they are expressly included in the Price.
- Delivery of the Works
5.1 Subject to clause 5.2 it is PPS’s responsibility to ensure that the Works start as soon as it is reasonably possible.
5.2 The Works commencement date will be put back and/or the completion date extended by whatever time is reasonable in the event that PPS claims an extension of time (by giving the Client written notice) where completion is delayed by an event beyond PPS’s control, including but not limited to any failure by the Client to:
(a) make a selection; or
(b) have the site ready for the Works; or
(c) notify PPS that the site is ready.
5.3 PPS may deliver the Works by separate instalments. Each separate instalment shall be invoiced and paid in accordance with the provisions in these terms and conditions.
5.4 Any time or date given by PPS to the Client is an estimate only. PPS shall not be liable for any loss or damage whatsoever due to failure by PPS to deliver the Works (or any part of them) promptly or at all, where due to circumstances beyond the reasonable control of PPS.
(a) where PPS is supplying Materials only, all risk for the Materials shall immediately pass to the Client on delivery and the Client must insure the Materials on or before delivery. Delivery of the Materials shall be deemed to have taken place immediately at the time that either;
(i) the Client or the Client’s nominated carrier takes possession of the Materials at PPS’s address; or
(ii) the Materials are delivered by PPS or PPS’s nominated carrier to the Client’s nominated delivery address (even if the Client is not present at the address).
(b) where PPS is to both supply and install Materials then PPS shall maintain a contract works insurance policy until the Works are completed. Upon completion of the Works all risk for the Works shall immediately pass to the Client.
6.2 Notwithstanding the provisions of clause 6.1 if the Client specifically requests PPS to leave Materials outside PPS’s premises for collection or to deliver the Materials to an unattended location then such materials shall always be left at sole risk of the Client and it shall be the Client’s responsibility to ensure the Materials are insured adequately or at all. In the event that such Materials are lost, damaged or destroyed then replacement of the Materials shall be at the Client’s expense.
6.3 The Client acknowledges and agrees that:
(a) where there is presence of plant or tree root growth and/or other blockages may indicate damaged pipe work and therefore where PPS is requested to merely clear such blockages, PPS can offer no guarantee against reoccurrence or further damage;
(b) in the event of collapse during the pipe clearing process, PPS will immediately advise the Client of the same and shall provide the Client with an estimate for the full repair of the damaged pipe work; and
(c) when PPS has commenced the Works, PPS is then required by law to continue the Works until completed.
6.4 In the event that any special equipment becomes stuck in the drain PPS will notify the Client immediately and PPS will reserve the right to halt all Works until such time as PPS and the Client agree upon any recovery costs of the equipment, including excavation. The additional charges will then become a variation in accordance with clause 4.2 and will be detailed in writing and charged on the basis of PPS’ quotation and will be shown as a variation on the invoice.
7.1 The Client shall ensure that PPS has clear and free access to the work site at all times to enable them to undertake the works. PPS shall not be liable for any loss or damage to the site (including, without limitation, damage to pathways, driveways and concreted or paved or grassed areas) unless due to the negligence of PPS.
- Dial Before You Dig
8.1 Location of underground services by a licensed service locator is mandatory prior to commencement of any works. “Dial Before You Dig” must be consulted and any potential underground services marked on site. Whilst PPS will take all care to avoid damage to any underground services the Client agrees to indemnify PPS in respect of all and any liability claims, loss, damage, costs and fines as a result of damage to services not precisely located and notified. If the Client requests PPS to engage the service locator then this shall be in addition to the Price.
(a) the Client has paid PPS all amounts owing to PPS; and
(b) the Client has met all of its other obligations to PPS.
9.2 Receipt by PPS of any form of payment other than cash shall not be deemed to be payment until that form of payment has been honoured, cleared or recognised.
9.3 It is further agreed that:
(a) until ownership of the Materials passes to the Client in accordance with clause 9.1 that the Client is only a bailee of the Materials and unless the Materials have become fixtures must return the Materials to PPS on request.
(b) the Client holds the benefit of the Client’s insurance of the Materials on trust for PPS and must pay to PPS the proceeds of any insurance in the event of the Materials being lost, damaged or destroyed.
(c) the production of these terms and conditions by PPS shall be sufficient evidence of PPS’s rights to receive the insurance proceeds direct from the insurer without the need for any person dealing with PPS to make further enquiries.
(d) the Client must not sell, dispose, or otherwise part with possession of the Materials other than in the ordinary course of business and for market value. If the Client sells, disposes or parts with possession of the Materials then the Client must hold the proceeds of any such act on trust for PPS and must pay or deliver the proceeds to PPS on demand.
(e) the Client should not convert or process the Materials or intermix them with other goods but if the Client does so then the Client holds the resulting product on trust for the benefit of PPS and must sell, dispose of or return the resulting product to PPS as it so directs.
(f) unless the Materials have become fixtures the Client irrevocably authorises PPS to enter any premises where PPS believes the Materials are kept and recover possession of the Materials.
(g) PPS may recover possession of any Materials in transit whether or not delivery has occurred.
(h) the Client shall not charge or grant an encumbrance over the Materials nor grant nor otherwise give away any interest in the Materials while they remain the property of PPS.
(i) PPS may commence proceedings to recover the Price of the Materials sold notwithstanding that ownership of the Materials has not passed to the Client.
- Personal Property Securities Act 2009 (“PPSA”)
10.2 Upon assenting to these terms and conditions in writing the Client acknowledges and agrees that these terms and conditions constitute a security agreement for the purposes of PPSA and creates a security interest in all Materials that have previously been supplied and that will be supplied in the future by PPS to the Client.
(iii) correct a defect in a statement referred to in clause 10.3(a)(i) or 10.3(a)(ii);
(b) indemnify, and upon demand reimburse, PPS for all expenses incurred in registering a financing statement or financing change statement on the Personal Property Securities Register established by PPSA or releasing any Materials charged thereby;
(c) not register a financing change statement in respect of a security interest without the prior written consent of PPS;
(d) not register, or permit to be registered, a financing statement or a financing change statement in relation to the Materials in favour of a third party without the prior written consent of PPS; and
(e) immediately advise PPS of any material change in its business practices of selling the Materials which would result in a change in the nature of proceeds derived from such sales.
10.4 PPS and the Client agree that sections 96, 115 and 125 of PPSA do not apply to the security agreement created by these terms and conditions.
10.6 The Client waives its rights as a grantor and/or a debtor under sections 142 and 143 of PPSA.
10.7 Unless otherwise agreed to in writing by PPS, the Client waives its right to receive a verification statement in accordance with section 157 of PPSA.
10.8 The Client shall unconditionally ratify any actions taken by PPS under clauses 10.3 to 10.5.
10.9 Subject to any express provisions to the contrary nothing in these terms and conditions is intended to have the effect of contracting out of any of the provisions of PPSA.
- Security and Charge
11.1 In consideration of PPS agreeing to supply the Materials, the Client charges all of its rights, title and interest (whether joint or several) in any land, realty or other assets capable of being charged, owned by the Client either now or in the future, to secure the performance by the Client of its obligations under these terms and conditions (including, but not limited to, the payment of any money).
11.2 The Client indemnifies PPS from and against all PPS’s costs and disbursements including legal costs on a solicitor and own client basis incurred in exercising PPS’s rights under this clause.
11.3 The Client irrevocably appoints PPS and each director of PPS as the Client’s true and lawful attorney/s to perform all necessary acts to give effect to the provisions of this clause 11 including, but not limited to, signing any document on the Client’s behalf.
- Defects, Warranties and Returns, Competition and Consumer Act 2010 (CCA)
12.1 The Client must inspect all Materials on delivery (or the Works on completion) and must within seven (7) days of delivery notify PPS in writing of any evident defect/damage, shortage in quantity, or failure to comply with the description or quote. The Client must notify any other alleged defect in the Materials/Works as soon as reasonably possible after any such defect becomes evident. Upon such notification the Client must allow PPS to inspect the Materials or to review the Works provided.
12.2 Under applicable State, Territory and Commonwealth Law (including, without limitation the CCA), certain statutory implied guarantees and warranties (including, without limitation the statutory guarantees under the CCA) may be implied into these terms and conditions (Non-Excluded Guarantees).
12.3 PPS acknowledges that nothing in these terms and conditions purports to modify or exclude the Non-Excluded Guarantees.
12.4 Except as expressly set out in these terms and conditions or in respect of the Non-Excluded Guarantees, PPS makes no warranties or other representations under these terms and conditions including but not limited to the quality or suitability of the Materials/Works. PPS’s liability in respect of these warranties is limited to the fullest extent permitted by law.
12.6 If PPS is required to replace any Materials under this clause or the CCA, but is unable to do so, PPS may refund any money the Client has paid for the Materials.
12.7 If PPS is required to rectify, re-supply, or pay the cost of re-supplying the Works under this clause or the CCA, but is unable to do so, then PPS may refund any money the Client has paid for the Works but only to the extent that such refund shall take into account the value of Works and Materials which have been provided to the Client which were not defective.
12.8 If the Client is not a consumer within the meaning of the CCA, PPS’s liability for any defect or damage in the Materials is:
(a) limited to the value of any express warranty or warranty card provided to the Client by PPS at PPS’s sole discretion;
(b) limited to any warranty to which PPS is entitled, if PPS did not manufacture the Materials;
(c) otherwise negated absolutely.
(a) the Client has complied with the provisions of clause 12.1; and
(b) PPS has agreed that the Materials are defective; and
(c) the Materials are returned within a reasonable time at the Client’s cost (if that cost is not significant); and
(d) the Materials are returned in as close a condition to that in which they were delivered as is possible.
12.10 Notwithstanding clauses 12.1 to 12.9 but subject to the CCA, PPS shall not be liable for any defect or damage which may be caused or partly caused by or arise as a result of:
(a) the Client failing to properly maintain or store any Materials;
(b) the Client using the Materials for any purpose other than that for which they were designed;
(c) the Client continuing to use any Materials after any defect became apparent or should have become apparent to a reasonably prudent operator or user;
(d) interference with the Works by the Client or any third party without PPS’s prior approval;
(e) the Client failing to follow any instructions or guidelines provided by PPS;
(f) fair wear and tear, any accident, or act of God.
12.11 PPS may in its absolute discretion accept non-defective Materials for return in which case PPS may require the Client to pay handling fees of up to twenty percent (20%) of the value of the returned Materials plus any freight costs.
12.12 Notwithstanding anything contained in this clause if PPS is required by a law to accept a return then PPS will only accept a return on the conditions imposed by that law.
- Intellectual Property
13.1 Where PPS has designed, drawn, written plans or a schedule of Works, or created any products for the Client, then the copyright in all such designs, drawings, documents, plans, schedules and products shall remain vested in PPS, and shall only be used by the Client at PPS’s discretion.
13.2 The Client warrants that all designs, specifications or instructions given to PPS will not cause PPS to infringe any patent, registered design or trademark in the execution of the Client’s order and the Client agrees to indemnify PPS against any action taken by a third party against PPS in respect of any such infringement.
13.3 The Client agrees that PPS may (at no cost) use for the purposes of marketing or entry into any competition, any documents, designs, drawings, plans or products which PPS has created for the Client.
- Default and Consequences of Default
14.1 Interest on overdue invoices shall accrue daily from the date when payment becomes due, until the date of payment, at a rate of two and a half percent (2.5%) per calendar month (and at PPS’s sole discretion such interest shall compound monthly at such a rate) after as well as before any judgment.
14.2 If the Client owes PPS any money the Client shall indemnify PPS from and against all costs and disbursements incurred by PPS in recovering the debt (including but not limited to internal administration fees, legal costs on a solicitor and own client basis, PPS’s collection agency costs, and bank dishonour fees).
14.3 Without prejudice to any other remedies PPS may have, if at any time the Client is in breach of any obligation (including those relating to payment) under these terms and conditions PPS may suspend or terminate the supply of Works to the Client. PPS will not be liable to the Client for any loss or damage the Client suffers because PPS has exercised its rights under this clause.
14.4 Without prejudice to PPS’s other remedies at law PPS shall be entitled to cancel all or any part of any order of the Client which remains unfulfilled and all amounts owing to PPS shall, whether or not due for payment, become immediately payable if:
(a) any money payable to PPS becomes overdue, or in PPS’s opinion the Client will be unable to make a payment when it falls due;
(b) the Client becomes insolvent or bankrupt, convenes a meeting with its creditors or proposes or enters into an arrangement with creditors, or makes an assignment for the benefit of its creditors; or
(c) a receiver, manager, liquidator (provisional or otherwise) or similar person is appointed in respect of the Client or any asset of the Client.
- Dispute Resolution
15.1 If a dispute arises between the parties to this contract then either party shall send to the other party a notice of dispute in writing adequately identifying and providing details of the dispute. Within fourteen (14) days after service of a notice of dispute, the parties shall confer at least once, to attempt to resolve the dispute. At any such conference each party shall be represented by a person having authority to agree to a resolution of the dispute. In the event that the dispute cannot be so resolved either party may by further notice in writing delivered by hand or sent by certified mail to the other party refer such dispute to arbitration. Any arbitration shall be:
(a) referred to a single arbitrator to be nominated by the President of the Institute of Arbitrators Australia; and
(b) conducted in accordance with the Institute of Arbitrators Australia Rules for the Conduct of Commercial Arbitration.
16.1 PPS may cancel any contract to which these terms and conditions apply or cancel delivery of Works at any time before the Works are commenced by giving written notice to the Client. On giving such notice PPS shall repay to the Client any sums paid in respect of the Price, less any amounts owing by the Client to PPS for Works already performed. PPS shall not be liable for any loss or damage whatsoever arising from such cancellation.
16.2 In the event that the Client cancels the delivery of Works the Client shall be liable for any and all loss incurred (whether direct or indirect) by PPS as a direct result of the cancellation (including, but not limited to, any loss of profits).
16.3 Cancellation of orders for products made to the Client’s specifications, or for non-stocklist items, will definitely not be accepted once production has commenced, or an order has been placed.
- Compliance with Laws
17.1 The Client and PPS shall comply with the provisions of all statutes, regulations and bylaws of government, local and other public authorities that may be applicable to the works.
17.2 The Client shall obtain (at the expense of the Client) all licenses and approvals that may be required for the works.
17.3 The Client agrees that the site will comply with any occupational health and safety laws relating to building/construction sites and any other relevant safety standards or legislation.
- Privacy Act 1988
18.1 The Client agrees for PPS to obtain from a credit reporting agency a credit report containing personal credit information about the Client in relation to credit provided by PPS.
18.2 The Client agrees that PPS may exchange information about the Client with those credit providers either named as trade referees by the Client or named in a consumer credit report issued by a credit reporting agency for the following purposes:
(a) to assess an application by the Client; and/or
(b) to notify other credit providers of a default by the Client; and/or
(c) to exchange information with other credit providers as to the status of this credit account, where the Client is in default with other credit providers; and/or
(d) to assess the creditworthiness of the Client.
The Client understands that the information exchanged can include anything about the Client’s creditworthiness, credit standing, credit history or credit capacity that credit providers are allowed to exchange under the Privacy Act 1988.
18.3 The Client consents to PPS being given a consumer credit report to collect overdue payment on commercial credit (Section 18K(1)(h) Privacy Act 1988).
18.4 The Client agrees that personal credit information provided may be used and retained by PPS for the following purposes (and for other purposes as shall be agreed between the Client and PPS or required by law from time to time):
(a) the provision of Works; and/or
(b) the marketing of Works by PPS, its agents or distributors; and/or
(c) analysing, verifying and/or checking the Client’s credit, payment and/or status in relation to the provision of Works; and/or
(d) processing of any payment instructions, direct debit facilities and/or credit facilities requested by the Client; and/or
(e) enabling the daily operation of Client’s account and/or the collection of amounts outstanding in the Client’s account in relation to the Works.
18.5 PPS may give information about the Client to a credit reporting agency for the following purposes:
(a) to obtain a consumer credit report about the Client;
(b) allow the credit reporting agency to create or maintain a credit information file containing information about the Client.
18.6 The information given to the credit reporting agency may include:
(a) personal particulars (the Client’s name, sex, address, previous addresses, date of birth, name of employer and driver’s licence number);
(b) details concerning the Client’s application for credit or commercial credit and the amount requested;
(c) advice that PPS is a current credit provider to the Client;
(d) advice of any overdue accounts, loan repayments, and/or any outstanding monies owing which are overdue by more than sixty (60) days, and for which debt collection action has been started;
(e) that the Client’s overdue accounts, loan repayments and/or any outstanding monies are no longer overdue in respect of any default that has been listed;
(f) information that, in the opinion of PPS, the Client has committed a serious credit infringement (that is, fraudulently or shown an intention not to comply with the Client’s credit obligations);
(g) advice that cheques drawn by the Client for one hundred dollars ($100) or more, have been dishonoured more than once;
(h) that credit provided to the Client by PPS has been paid or otherwise discharged.
- Building and Construction Industry Security of Payments Act 1999
19.1 At PPS sole discretion, if there are any disputes or claims for unpaid Goods and/or Services then the provisions of the Building and Construction Industry Security of Payments Act 1999 may apply.
19.2 Nothing in this agreement is intended to have the affect of contracting out of any applicable provisions of the Building and Construction Industry Security of Payments Act 1999 of New South Wales, except to the extent permitted by the Act where applicable.
20.1 The failure by PPS to enforce any provision of these terms and conditions shall not be treated as a waiver of that provision, nor shall it affect PPS’s right to subsequently enforce that provision. If any provision of these terms and conditions shall be invalid, void, illegal or unenforceable the validity, existence, legality and enforceability of the remaining provisions shall not be affected, prejudiced or impaired.
20.2 These terms and conditions and any contract to which they apply shall be governed by the laws of the state in which the Seller has its principal place of business, and are subject to the jurisdiction of the courts in that state.
20.3 Subject to clause 12 PPS shall be under no liability whatsoever to the Client for any indirect and/or consequential loss and/or expense (including loss of profit) suffered by the Client arising out of a breach by PPS of these terms and conditions (alternatively PPS’s liability shall be limited to damages which under no circumstances shall exceed the Price of the Works).
20.4 The Client shall not be entitled to set off against, or deduct from the Price, any sums owed or claimed to be owed to the Client by PPS nor to withhold payment of any invoice because part of that invoice is in dispute.
20.5 PPS may license or sub-contract all or any part of its rights and obligations without the Client’s consent.
20.6 The Client agrees that PPS may amend these terms and conditions at any time. If PPS makes a change to these terms and conditions, then that change will take effect from the date on which PPS notifies the Client of such change. The Client will be taken to have accepted such changes if the Client makes a further request for PPS to provide any Works to the Client.
20.7 Neither party shall be liable for any default due to any act of God, war, terrorism, strike, lock-out, industrial action, fire, flood, storm or other event beyond the reasonable control of either party.
20.8 The Client warrants that it has the power to enter into this agreement and has obtained all necessary authorisations to allow it to do so, it is not insolvent and that this agreement creates binding and valid legal obligations on it.
© Copyright 2013 Permanent Plumbing Solutions. All rights reserved Terms